South American Oil Refinery

Americas

ICC Arbitration Panel awards contractor only 20% of its claim

What we did

HKA was retained by counsel on behalf of the owner of an oil refinery in South America to rebut claims in excess of US$50 million brought by the civil contractor. The claims for increased costs related to purported delay and disruption caused by late design information during the refinery expansion project.

HKA authored two-200 plus page reports and testified on schedule delay and damages issues at the ICC arbitration proceedings.

Outcomes

The tribunal awarded the civil contractor only US$10.8 million of its US$50 million claim, not including prejudgment interest.

Project Details

Client

Confidential
Year

2017
Value

US$50 million
Services

Delay and Disruption Analysis
Sectors

Construction and Engineering, Oil and Gas

RELATED PROJECTS

South American Oil Refinery

Americas

ICC Arbitration Panel awards contractor only 20% of its claim

What we did

Outcomes

Independent Quantum Expert Opinion of Highway Maintenance Contract

Europe

UNSW Capital Projects Sustainability Framework

Oceania

Subsea Cable Installation & Trenching Operations

Asia

Coal-fired power plant

Asia

Missouri Power Plant

Americas

Independent Commercial, Cost & Risk Review of Road Development

Europe

Sydney Water, Partnering for Success (P4S)

Oceania

Subsea Interconnector Cable Failure

Europe

Coal-fired power plant

Americas

Spent Nuclear Fuel Verdicts & Settlements

Americas

Independent Quantum Expert Review of Maintenance Contract

Europe

Melbourne Airport Rail

Oceania

Energy and Telecom Cable Manufacturer

Americas & Asia

Water desalination plant

Americas

Longview Power Plant

Americas

Major Light Rail Transit

Americas

Liquefied Natural Gas (LNG) Project Australia

Oceania

Clean Fuels Project

Middle East

Offshore refinery contractor performance review

Asia

University of North Carolina Hospitals

Americas

Two New Venues

Middle East

Residential Development

Middle East

Nuclear Power Plant Decommissioning

Americas

WestConnex Rozelle Interchange

Oceania

Power Plant

Americas

A Major Teaching & Research Hospital

Europe

Natural Gas-Fired Power Plant

Asia

Global chemicals manufacturer

Americas & Europe

Major Nuclear Power Plant

Americas

Nuclear Power Plant

Americas

Industrial Manufacturing Facility

Europe

Business Park, Surrey

Europe

Major Canadian Utility Commercial Damages Matter

Americas

New School Campus, Ultimo Primary School

Oceania

Subsea Power Cable Failure

Asia

Highway Rock Cuttings

Middle East

Share our Space Program

Oceania

Allseas & Pioneering Spirit